Digital Capital Limited v Genesis Mining Iceland E.H.F.

This is a dispute arising out of an agreement for the provision by the Claimant to the Defendant of certain regulatory and software services. Each party alleges that the other repudiated the agreement. The Claimant’s primary claim is for payment of certain invoices allegedly payable under the terms of the agreement. The Defendant alleges that the Claimant failed to provide the services which it had contracted to provide and was thereby in repudiatory breach of contract which it purported to accept by its solicitors’ letter dated 3 June 2019. In consequence, it was said, not only was the Defendant not obliged to pay the invoices in question, but it was also entitled to recover payments previously made on grounds of total failure of consideration. The Claimant denies that it was in breach of the agreement as alleged and maintains that the Defendant’s purported termination was itself a repudiatory breach which the Claimant formally accepted on 1 October 2019.

In the result, I have before me:

Until 21 June 2021, the Claimant was represented by Davis Woolfe Ltd. Since that date it has been represented by its director, Mrs Dorotea Arlov, acting in person. The Defendant is represented by Mr Terence Bergin QC of counsel. Despite the fact that Mrs Arlov is not a qualified lawyer, she showed herself to be more than capable of understanding and complying with the necessary procedures for litigating disputes in court and indeed handled the hearing with considerable skill and ability – no mean feat, given that English is not her native language. As one would naturally expect, Mr Bergin has provided every reasonable assistance in that regard consistent with his duty to his own client and I gratefully acknowledge his patience in that regard. While the Court put certain questions to Mrs Arlov and the other witnesses, I explained that this was only to the extent that such questions might properly have been expected to be put if the Claimant had been legally represented and/or to elucidate some of the evidence given. It was made clear to all parties that this was done solely in order to ensure that the Claimant’s case was properly put before the Court and not in order to make a case for one side or the other. In the result, I am satisfied that Mrs Arlov has had a proper opportunity to put the Claimant’s case before the court.

I am grateful to both her and Mr Bergin for the clarity of their submissions.

Mr Jakov Dolić is a German citizen and a civil engineer by training who developed an early interest in cryptocurrencies. In about 2013, he met Dr Marco Krohn and Mr Marco

In 2014, Genesis Mining Hong Kong was created as a platform for offering mining contracts to customers worldwide. Mr Dolić was the sole beneficial owner and CEO of Genesis Mining Hong Kong until he formally resigned on 20 December 2018. The Defendant, Genesis Mining Iceland EHF, (“Genesis Iceland”) was created as a wholly owned subsidiary of Genesis Mining Hong Kong in order to own and operate a server farm in Iceland. Bitcoin mining involves vast amounts of computer power and Iceland was a particularly attractive location due to its low energy costs and cool climate. Neither Dr Krohn nor Mr Streng was a shareholder in either Genesis Mining Hong Kong or Genesis Iceland. References to “Genesis” in the remainder of this judgment are to the Genesis interests generally. Where specific reference to the Defendant is required, I refer to Genesis Iceland.

One of the problems facing people who held assets in cryptocurrency at that time was the difficulty of accessing the ordinary banking system and spending bitcoins or other crypto assets in normal retail transactions. This led Mr Dolić in about 2015 to conceive an idea for Genesis to create its own “bank” that would act a bridge between cryptocurrencies on the one hand and the so-called FIAT currencies used in ordinary banking operations on the other, thereby making cryptocurrencies such as bitcoin more accessible. One important aspect of the concept was to provide customers with a debit card facility which would allow them to spend bitcoin as easily and in the same way as ordinary currencies. Customers would therefore not only be able to deposit and hold cryptocurrency and exchange it for other cryptocurrencies, but also to “spend” it in conventional retail transactions by converting it instantaneously into FIAT currency. This in turn required a mainstream banking facility to be set up for the debit cards as well as an underlying technology system enabling rapid exchange of the cryptocurrency held on customer accounts with FIAT currencies accepted by retailers. The project, initially named Guaroo, became known as the “Genesis Wallet” or “G Wallet”.

In October 2015, Mr Dolić moved from Germany to Croatia where he purchased a penthouse apartment from a well-known Croatian banker, Mr Zoran Sikirica. Mr Dolić had never previously met Mr Sikirica but, knowing that he was a banker, he invited him to support Genesis in setting up a bank to realise the Guaroo idea. Mr Sikirica suggested that the regulatory obligations of a bank would be unnecessarily onerous and that a better and cheaper idea would be to establish an e-money institution (“EMI”). He told Mr Dolić that he had a friend, Mr Tonci Perković, who was an electrical engineer working with him on various projects who could assist in obtaining an e-money licence (“EML”).

According to Mr Dolić, Mr Sikirica did not suggest that Mr Perković had any particular expertise and he did not ask for or take up any references or investigate Mr Perković’s credentials or suitability for the project. He was content to rely on Mr Sikirica’s recommendation. He explained to me that he as far as he was aware, Mr Perković was an electrical engineer and did not have any banking experience but he assumed (albeit without apparently taking any steps to confirm the position) that Mr Sikirica would lead the project and effectively tell Mr Perković what needed to be done. In fact, although not a banker, Mr Perković had considerable experience of software programming and

In the event, Mr Sikirica dropped out of the picture. Mr Dolić nonetheless decided to pursue the project with Mr Perković in order to see what could be achieved. The impression he gave me was that he had accumulated considerable wealth through the appreciation in value of his cryptocurrency assets and that he was prepared to invest money in the venture on a speculative basis. He also told me that he liked and trusted Mr Perković. Sometime later, he was introduced by Mr Perković to Mrs Arlov, although he could not remember whether this was in late 2015 or early 2016.

The first step was to establish a company to obtain and hold an EML. Mr Perković and Mrs Arlov considered the possibility of obtaining an EML in Croatia but concluded that the market perception of a Croatian EMI would not be favourable and that it would be better to establish the company in England as this offered the best access to FinTech companies and the regulatory requirements were relatively straightforward, even though the costs would be higher. Subsequently it was also agreed that Mr Perković and Mrs Arlov would provide a discrete part of the software for the project.

Mr Dolić agreed to provide the necessary funding and Digital Capital was incorporated on 9 June 2016 for this purpose. It was not in contention that both Mr Sikirica and Mr Perković stressed the importance for regulatory reasons that Digital Capital should be independent of the Genesis interests and should not be seen to be controlled by the Genesis group as this would create a potential conflict of interest. The majority shareholders and directors of Digital Capital were accordingly Mrs Arlov and Mr Perković’s son, Bruno Perković, the latter being in charge of marketing and user experience. Dr Krohn had a 9% shareholding. A third director joined in 2017, Mr Gareth Lewis, who was responsible for compliance. Although Genesis Iceland turned out to be Digital Capital’s sole client up to the time of the present dispute, it was always contemplated that Digital Capital as an EMI would also offer services to other clients thereby creating a revenue stream for the new company.

In exchange for the provision of funds by Mr Dolić via the Genesis group, there was an informal understanding that once the Genesis Wallet was up and running, the majority shareholding would be transferred to the Genesis group but that Mrs Arlov and Mr Perković would have the option to buy back 50% of the company for £1 million together with a 2% stake in a Genesis company to be incorporated in due course as a front company for the Genesis Wallet. This agreement was never documented.

Digital Capital obtained its EML on 13 July 2017 and since that date has traded as an FCA authorised entity.

In October 2017, Mr Dolić stepped back from his executive roles in the Genesis group although he remained on the register as the CEO of both Genesis Mining Hong Kong and Genesis Iceland until his formal resignation on 20 December 2018. I understand his interests to have been bought out by Dr Krohn and Mr Streng who are currently co- owners and co-directors of the companies. Both companies continue to exist although the Genesis group under its new management has withdrawn from the cryptocurrency

On 12 January 2017, a detailed service agreement (the “Agreement”) for the Genesis Wallet project was signed by Mrs Arlov on behalf of Digital Capital as service provider and Mr Dolić on behalf of Genesis Iceland as client. Mr Dolić said that he regarded the Agreement first and foremost as a way of indirectly providing funding to the Claimant company without it appearing to have been financed by Genesis. He therefore signed it without reading it first or caring very much what was in it beyond asking what the total amount payable would be. This is the Agreement which has given rise to the dispute between the parties.

The Agreement contained detailed provisions regarding the scope of the services that Digital Capital and Genesis Iceland respectively were to provide in relation to the project. The most relevant provisions of the Agreement are set out in Appendix A to this judgment. In very broad terms, the Genesis Wallet consisted of two parts:

Under the Agreement Digital Capital was to provide the core software platform providing all the back-end functions of the Genesis Wallet. This covered everything relating to physical payments, including account opening, payment processing, issuing of payment cards, wire transfers and currency exchange. Digital Capital also undertook to provide regulatory set-up by the end of 2017 covering all work related to regulatory requirements, including obtaining the all-important EML. For its part, Genesis Iceland was to provide the front-end crypto platform through which customers could request that their cryptocurrency be exchanged, transferred to another wallet or paid to a third party. This work was outsourced by Genesis Iceland to a third party IT service provider, Barrage d.o.o. (“Barrage”).

A detailed list of the services to be provided by Digital Capital was contained in Appendix 1 to Schedule 1 of the Agreement. Reference will be made to certain parts of this list in the course of the judgment. For present purposes it is sufficient simply to note that Appendix 1 contained the following provisions:

The payment provisions set out in Schedule 1 to the Agreement can be summarised as follows:

I heard oral evidence of fact on behalf of the Claimant from Mrs Arlov and Mr Tonci Perković. Mr Perković’s witness statement was in Croatian and he gave evidence through an interpreter. On behalf of the Defendant, evidence was given orally by Mr

It was unfortunate that none of the Defendant’s witnesses was able, for one reason or another, to speak with authority or personal knowledge in relation to many of the relevant matters. This was not through any fault of theirs but because they had either not been involved on a day-to-day basis or because they had only participated in part of the story. I was informed by Mr Bergin that the Defendant was unable to call certain relevant personnel because they were no longer employed by the Defendant. That is always a hazard of litigation, but the fact remains that I was left without direct evidence from some of the key players.

It was a failing of all the factual witnesses to greater or lesser degree that they often did not answer questions directly but instead offered lengthy explanations by reference to prior or subsequent events. Each of them also had a tendency to argue the case rather than simply answering the questions put.

Nonetheless, I found both Mrs Arlov and Mr Perković to be witnesses of truth, whose account of their actions was coherent, credible and consistent with the documents.

Mrs Arlov was cross-examined at some length on various notes that she had made of meetings and telephone conferences and Mr Bergin was critical of her oral explanations of these notes on the basis that it diverged from the written text. I found these criticisms to be generally misplaced. As Mrs Arlov explained, these were notes that she had made during the actual course of the relevant meetings and calls, often while she was simultaneously having to translate for one or other of the participants. They were therefore necessarily in abbreviated summary form and were never intended to serve as a transcript of the entire discussion, being only for her internal use. Had she known at the time that they would be subjected to detailed forensic analysis, no doubt they would have been considerably amplified. As it was, I regard them as a reliable record of what transpired, the more so since (i) it is difficult for truly contemporaneous notes (as these were) to do other than reflect what is said in the order in which it is said and (ii) they were never intended for public consumption or sent to the Defendant, so that they are inherently unlikely to been carefully worded or “spun” in order to create a particular impression.

Mr Dolić did not impress me as a witness. He was never involved in the day-to-day running of the project and had virtually nothing to do with the Genesis group after October 2017. His witness statement gave the impression that he could not remember anything at all about the various meetings in which he participated and he confirmed at the outset of his oral evidence that he could no longer recall specific meetings as there were so many and it was so long ago. As his cross-examination proceeded, however, he adopted positions which not only had not previously featured in his written evidence but constantly shifted under cross-examination.

He also seemed to have a very laissez faire attitude to his business dealings as exemplified by his account of the genesis of the Agreement with Digital Capital and the circumstances in which he came to sign it. On his own evidence, he was the sole beneficial owner and CEO of the Defendant and thus the only person with any corporate authority to act on its behalf. Having conceived the idea of the Genesis Wallet, he decided on behalf of the Defendant to invest a substantial amount of money in the idea

It may well be, as he maintained in his oral evidence, that his business style was informal and that he often did not document transactions formally, preferring to proceed on trust in accordance with his gut instincts but with this egregious lack of attention to detail, it is hardly surprising that Mr Dolić had very little specific or detailed recollection of events. Suffice it to say that I was not inclined to place reliance on anything he said which was contrary to his written evidence or which was not supported by the contemporaneous documentation.

Dr Krohn was a theoretical physicist by training with a background in banking. He had not played any part in negotiating the Agreement with Digital Capital and he was not concerned in the day-to-day running of the Genesis Wallet project. He was at pains to stress that his involvement was only at a very high level – being essentially limited to occasions when a problem arose which could not be sorted out by those handling matters day-to-day. Otherwise, he trusted the latter to get on with things. His only significant involvement was from May 2018 onwards and even then he apparently relied almost exclusively for his information on what he was told by others. Like Mr Dolić, Dr Krohn could not really remember very much at all. Surprisingly, he did not even know whether he was a director of Genesis Iceland. Nor, it was plain, did he take very much interest in the company.

Mr Kaiser was an accountant. He was not a technical person and his expertise was in finance, not programming. He had been introduced to Genesis through Mr Streng, who was his cousin. Like Dr Krohn, he had no involvement with the project before mid- 2018 when he was asked to carry out a review with a view to handing it over to a Mr Matthias Endriss who was shortly to assume responsibility as project manager. I found his some of his evidence difficult to reconcile with the documentary record, which did not support his suggestion that there had been frequent internal discussions and complaints about poor performance by Digital Capital. He sometimes appeared to be reluctant to answer questions and was inclined on occasions to be argumentative.

Mr Ivanšić was called as a representative of Barrage. The person who might have been able to give the most assistance to the court from Barrage was in fact Mr Berislav Brajković but unfortunately he had left the company in 2020. As it was, Mr Ivanšić was a designer, not a software engineer, and was not in any event involved in the project on a day-to-day basis. He therefore had little direct knowledge of the relevant events and his evidence was accordingly of limited assistance. He too I found to be rather argumentative.

As a matter of general impression, none of the Defendant’s witnesses had played any part in the day-to-day running of the project or involved themselves in the detail. Indeed, none of them apart from Dr Krohn had any technical software expertise at all. It is hardly surprising that they could not speak with any real authority as to what was or was not happening on the ground. The people who might have been able to give more help in this respect, namely Mr Endriss, Mr Ablay and Mr Brajković, did not give evidence. However, it was striking that while the Defendant’s witnesses all professed

The problem was that none of this featured in the contemporaneous documents. I do not suggest that this evidence was not honestly given. It is commonplace for memories to become subconsciously distorted in the context of litigation: see Gestmin SGPS SA v Credit Suisse (UK) Ltd, [2013] EWHC 3560 (Comm) at [16]-[22]. What it does mean, however, is that I have relied first and foremost on the contemporaneous documentation in forming my view of the facts as set out below and that where the evidence of the Defendant’s witnesses is in conflict with that of Mrs Arlov and Mr Perković, I prefer the latter.

The parties each called one expert witness to give evidence before me on the technical issues. Digital Capital’s expert was Dr Tonko Kovačević, who is currently a professor in Electrical Engineering at the University of Split, having previously also worked at the Teaching Institute for Public Health in Split as Head of Department for planning, developing and maintaining communication and computer systems. The Defendant’s expert was Dr Gillian Hunt, an independent IT consultant with specialist expertise in system management, software development, system design and implementation and project management. Their evidence is discussed in connection with the technical issues below.

I do not attempt to summarise the evidence given by each of the factual witnesses individually. If a particular piece of evidence is not referred to, that does not mean that I have failed to take it into account.

Much of the factual narrative was controversial, in particular as to what was or was not discussed and agreed at various meetings. The narrative below sets out my findings on my assessment of the evidence before me.

In 2014, Mrs Arlov founded a Croatian company called Rolling Capital d.o.o. (“Rolling Capital”) which specialised in FinTech. Mrs Arlov was the sole shareholder in Rolling Capital and project managed the small software projects which it undertook.

Towards the end of 2015, Mr Perković mentioned the Genesis project to Mrs Arlov and suggested that she might be well placed to provide the FinTech services required by Genesis given her background in FinTech and software project management. As already noted above, Digital Capital was incorporated on 9 June 2016. A first meeting with Genesis took place on 15 July in Munich.

In early September 2016, Mrs Arlov was introduced to London Multigames Ltd (“LMG”) as a company which might be able to assist in setting up an e-wallet. Mrs Arlov and Mr Perković met LMG on 15 September and discussed the possibility of developing a bespoke software platform by utilising part of an existing LMG system and then introducing additional functionalities and integrating further modules sourced

Mrs Arlov considered it a good idea to separate the regulated financial business operated by Digital Capital from any software business. Accordingly, on 22 September 2016, One Click Pay Ltd (“One Click”) was incorporated as a separate company solely owned by Mr Perković, although Mrs Arlov was also a director and company secretary. While the primary impetus to establish One Click at that precise time may have been the proposed Genesis Wallet project, it was never intended that One Click’s operations would be confined to this project, the ultimate aim being to develop innovative technologies in the FinTech field generally. Nonetheless, in relation to the Genesis Wallet project One Click operated alongside Digital Capital.

In his cross-examination of Mr Perković and in his submissions, Mr Bergin sought to make much of the fact that Mr Perković seemed frequently to have acted and spoken on behalf of Digital Capital despite having no formal role in the company. The suggestion seemed to be that Digital Capital was concealing the involvement of One Click.

I accept that there was an extremely close relationship between the two companies and that there were many occasions when Mrs Arlov or Mr Perković did not draw a distinction between them. However, I find nothing untoward in this. For legal and regulatory purposes the companies were clearly distinct, and rightly so. But in practical terms, they were working synchronously on the Genesis Wallet project and, unless and until there was a dispute between them, they could be expected to speak with one voice. Since development of the software had been outsourced by Digital Capital to One Click, I find it unsurprising that Mr Perković sometimes took the lead in technical matters and, given that his son was the other majority shareholder, had a close interest in Digital Capital itself. It does not appear to me that either Mrs Arlov or Mr Perković attempted actively to conceal the relationship between the companies and, despite Mr Bergin’s eloquence, I fail to see that Genesis’ knowledge or lack of knowledge about One Click’s role in any way impinges on the dispute. The relevant obligations under the Agreement were assumed by Digital Capital and it was entitled to fulfil them through outsourcing to third parties if it chose in the same way that Genesis Iceland relied on a third party IT provider, Barrage, to develop the front-end crypto platform for which it was responsible under the Agreement.

The relationship between Digital Capital and One Click was formalised on 17 November 2016 in an IT & Customer Support Service Level Agreement, whereby One Click undertook to provide IT consultancy and customer support services to Digital Capital. This was before Digital Capital had concluded any contract with Genesis Iceland and, as originally drafted, this agreement did not expressly cover the development of software by One Click.

In fact, by this time, One Click had already concluded an agreement with LMG for the provision of software development services. Again, it is my understanding that the scope of the agreement between One Click and LMG was not limited to the Genesis Wallet project (the precise details of which had of course not yet been agreed) but that

On 12 January 2017, the Agreement between Digital Capital and Genesis Iceland was signed by Mrs Arlov and Mr Dolić as described above. No lawyers were involved in preparing the agreement which seems to have been drafted by Digital Capital.

On 19 June 2017 a telephone conference took place between Mrs Arlov, Dr Krohn and Mr Marc Ablay, who was responsible for the technical aspects of the Genesis Wallet project on the Genesis side. As she did with all meetings and calls, Mrs Arlov took contemporaneous manuscript notes.

During the call, the options for software provision were discussed. Digital Capital had received an offer from a Croatian company called ABBA d.o.o. which had previously developed software of this nature¹ but the maintenance price was considered to be far too high, some €500,000 per month. Mrs Arlov therefore expressed a preference for developing Digital Capital’s own back-end system into which they would integrate various modules. I accept that when Mrs Arlov referred to “we”, she was using it in a loose sense to refer to Digital Capital and such sub-contractors as it chose to use. By the same token, when Genesis personnel used the term “we”, they were likewise referring collectively to people and companies with responsibility for matters on the Genesis side of the contractual line. Dr Krohn asked how long it would take for Digital Capital to create its own platform and was given a rough estimate of one year. Mr Ablay said that Genesis Iceland was working on its own platform which would take at least 1-1½ years more to develop.

On 30 June 2017, Digital Capital and One Click executed an Annex to their Service Level Agreement expressly providing for the provision of software services and setting out the specifications for an e-wallet platform. While not exclusively applicable to the Genesis Wallet project, the Annex was clearly prompted and necessitated by the Agreement and thus included many of the features which Digital Capital had undertaken to provide to Genesis Iceland.

Meanwhile, One Click had been working with LMG and in early July 2017, LMG sent an application programming interface (“API”) for a payment gateway that allowed account top-ups via existing cards and integration with a number of banks processing the card payments. The payment gateway was one of the modules that had been ordered by One Click from LMG and was to be integrated into the Digital Capital core software solution. The API was the mechanism by which the integration was to be achieved.

On 13 July 2017, Digital Capital obtained its EML from the FCA and on 25 August 2017, Mr Perković informed Mr Dolić by WhatsApp that they had also passed the necessary compliance procedures for a bank in Estonia, LHV Bank, with whom Digital Capital entered into an Internet Banking Agreement and Service Agreement on 28 August.

On 18 October 2017, Mr Perković contacted Mr Dolić and told him that the legal formalities for the debit cards were just being finalised but that there were some strategic matters which needed to be discussed before the next step. These included: software, acquiring partners, the KYC provider, card design, BIN sponsorship, FX provider and the model for integration with the Guaroo platform, which I understand to be a reference to the Genesis front-end platform. However, Mr Dolić had health problems at that time and told Mr Perković to contact Dr Krohn for anything urgent.

It appears that Mr Dolić effectively left the Genesis group at around this time although, as noted in paragraph 15 above, he remained on the company register as the sole director. He nonetheless continued to participate in various meetings and calls as appears below. Moreover, Mrs Arlov and, in particular, Mr Perković clearly regarded him as a “go to” person in relation to the project – understandably, since the whole concept had been his brainchild.

On 13/14 November 2017, a meeting took place in Munich attended by Mrs Arlov, Mr Perković, Mr Dolić, Dr Krohn and Mr Ablay. Mr Ablay was unable to be present on 13 November, so Mrs Arlov gave a short presentation about PSD2 (a European directive relating to electronic payments which was shortly due to come into force) and confirmed that the regulatory set-up had been completed. The meeting continued the following day, this time with Mr Ablay in attendance. Mrs Arlov drew a schematic diagram of the system and Mr Ablay asked about the status of the Digital Capital platform. Mr Perković indicated that the first functionalities of the software had been developed, including account opening, internal and external transfer, reporting and preparation for connection with third party providers. He thought it could be finished in the next 8-9 months. However, a revised offer had also been received from ABBA which was much lower than previously indicated – around €10,000 rather than

In answer to a question from Dr Krohn, Mrs Arlov explained that ABBA had indicated that it could adjust an existing platform and that this would only take 3-4 months. She therefore proposed that Digital Capital start working with ABBA. In evidence, she explained that Digital Capital had nothing to lose. The costs now being suggested by ABBA were comparatively low and if it was able to provide a satisfactory system sooner than Digital Capital could complete its own system, then so much the better as the aim was to go live as quickly as possible. (Mrs Arlov’s explanation was substantially confirmed by Mr Dolić in his oral evidence.) If not, Digital Capital would still have its own system procured through One Click. Mr Ablay responded that the Genesis platform would not be ready for at least a year but that this sounded like a good plan. It was therefore agreed that Mrs Arlov would arrange a meeting with ABBA to be attended as well by Genesis’ IT services provider, Barrage.

Further discussion also took place about the design for the debit cards and it was agreed that Fedja (I assume Mr Ivanšić) would provide this. Mrs Arlov also presented various connectors for the card processing, KYC and payment gateway.

Mrs Arlov was cross-examined at some length by Mr Bergin about the conclusions set out in her note of the meeting which stated that Mr Dolić would check the regulatory set-up together with Mr Rauth. It was suggested to her that Mr Dolić could not possibly have agreed to do this as he had no expertise in compliance and had not been involved in the regulatory set-up and that here note was therefore unreliable. I reject this suggestion. The fact that Mr Dolić himself had no compliance background (which was not in dispute) is not inconsistent with him having agreed to ensure that the regulatory set-up was checked by others, principally, it would seem, Mr Rauth who was Mrs Arlov’s only point of contact in relation to compliance matters.

The meeting with ABBA took place at the end of November 2017 in Zagreb. By this time, Mrs Arlov had sent Barrage the APIs for the connectors discussed at the 13/14 November meeting. On 27 November, a preliminary meeting took place between Digital Capital, Genesis and Barrage. It appears from Mrs Arlov’s note that much of the discussion was about complaints that Genesis Iceland had received from mining customers who had not received the payouts they were expecting. The reason for this was explained to me in oral evidence but as it has no direct bearing on the Genesis Wallet project, I do not address it further.

The following day, representatives from ABBA also attended. Mrs Arlov gave a short presentation about PSD2 and asked if ABBA could create all the necessary technical documentation. ABBA was apparently not able to provide an answer there and then and indicated that it would also need information about the Genesis platform in order to create the necessary APIs. Mr Brajković of Barrage agreed to create the technical specification which Digital Capital would then provide to ABBA.

After the ABBA representatives had left, there was further discussion. Mrs Arlov’s note (on which she was not cross-examined) suggests that Mr Brajković thought that the ABBA solution might work, while the Genesis representatives felt that ABBA had not completely understood the entire system. As a result, it was concluded that Digital Capital should continue to work on its own platform but hire ABBA at its own cost as a plan B. Mrs Arlov also noted:

On 12 December 2017, Mr Dolić and Mrs Arlov signed a confirmation that the regulatory set-up had been fully completed in accordance with the Agreement and that Digital Capital was accordingly entitled to payment of £800,000. It is not in dispute that this amount was duly paid. A further amendment to the service agreement between Digital Capital and One Click was agreed on 28 December 2017 to reflect additional work to be carried out by One Click in relation to the integration with the crypto platform which required bespoke API’s based on the technical specification for that platform.

On 10 January 2018, Genesis Iceland paid the second instalment of £800,000 due to Digital Capital under the Agreement as an advance payment in respect of the ongoing software set-up. From this date Digital Capital began to submit monthly invoices for operational fees and (from February 2018) also maintenance fees as contemplated by the Agreement.

In accordance with the course of action agreed at the November meeting (see paragraph 59 above), Digital Capital entered into a Software Service Agreement with ABBA on 31 January 2018. This required an upfront payment of €150,000 by Digital Capital and ongoing maintenance fees payable from 1 June 2018.

On 19 March 2018, Mr Brajković sent a link for the API to the crypto platform as had been requested by ABBA. Since it would be necessary to integrate with ABBA’s core banking system, he also requested ABBA’s API link and a test server with which to start development. Mr Brajković suggested that it would be a good idea to establish development groups so that the people working on integration could communicate regularly. He repeated the request for ABBA’s API documents on 22 March. Mrs Arlov’s evidence was that she never received these from ABBA although she believed that ABBA and Barrage may also have been in direct communication about it. However, it seems that she was able to pass on at least one of ABBA’s API connectors to Barrage on 30 March.

By the end of March 2018, Digital Capital had concluded agreements with several providers whose products were to be integrated into the core banking system, including the following:

Mrs Arlov sent the technical documentation relating to these providers to Barrage and there was some discussion about them, the details of which do not matter for present purposes.

In April 2018, Ms Jessica Sanches joined Genesis. As she was new to both Genesis Mining and the Genesis Wallet she requested a meeting with Mrs Arlov and Mr Perković in order to understand more about the project. They accordingly met in London on 20 April. As appears from Mrs Arlov’s contemporaneous note, she and Mr Perković gave a short presentation of the system and explained that further input was required from Genesis Iceland concerning projections, design and technical details. Ms

On 24 April 2018, Digital Capital concluded an agreement with a debit card manufacturer. She emailed Ms Sanches the same day confirming that Digital Capital had received four Mastercard BINs and attaching (i) the proposed card designs received from Barrage; (ii) a price list; and (iii) a table to be filled out by 26 April 2018 stating how many pieces of each design should be ordered initially. She informed Ms Sanches that delivery would take 8 weeks and that it was therefore necessary to estimate what stock of cards was required. It will be recalled that the Go Live date contemplated by the Agreement was 18 July 2018 which was only about 11 weeks distant.

A further meeting with Genesis and Barrage took place in Munich on 8 May 2018 attended by Mrs Arlov, Mr Perković, Dr Krohn, Mr Kaiser, Ms Sanches, Mr Brajković and Mr Ivanšić. Mr Kaiser had not previously been involved in the Genesis Wallet project. He was in any event an accountant and, on his own admission, not a technical person. Dr Krohn could not recall much, if anything of what transpired at this meeting. I accept Mrs Arlov’s note as an accurate summary of the points discussed.

At the meeting, Mr Brajković indicated that the Genesis crypto platform was running behind schedule and expressed doubts as to whether it would be finished before December. This was the first time that Digital Capital had been made aware of any delay on the Genesis side and it clearly rendered the 10 July 2018 Go Live date wholly unrealistic. Mrs Arlov recapped the position regarding PSD2 authorisation and said that the Digital Capital software was nearly finished, requiring another 2-3 months in order to finalise the integration with the card provider. She suggested that a presentation in August or September might be possible. As regards ABBA, she said that Digital Capital was unhappy with ABBA’s communication and doubtful as to the quality of its system. The agreement with ABBA required delivery of a test version of the system by 1 May 2018 and a live version by 15 June. However, neither of these deadlines had been met.

The question of the card order previously raised with Ms Sanches was mentioned again and Mrs Arlov was told that someone would contact her. She also stated that Digital Capital urgently needed certain usage projections from Mr Kaiser as well as the technical specifications from Barrage so that it could start work on integration as soon as possible.

A further matter raised was whether there would be changes in the company carrying the Genesis Wallet project and how this would work from an agency point of view. Genesis explained that it was working on the incorporation of a company in

On 1 June 2018, Mr Ivanšić circulated an email within Genesis (not copied to Digital Capital or Mr Perković) indicating that Barrage was intending to release the Genesis Wallet in mid-June to a limited number of users for cryptocurrencies only. It is clear from this email that integration with the Digital Capital FIAT platform was not contemplated imminently but there is no suggestion that this was due to any delays or failings on the part of Digital Capital. In answer to a request for demonstration, Mr Ivanšić provided a link to some design mock-ups on 4 June 2018. It also appears that a meeting was held between Barrage and Mr Endriss two weeks later to discuss this launch.

Meanwhile, on 14 June 2018, LMG had sent through to Digital Capital some front-end software for the purpose of testing Digital Capital’s back-end system and, in particular, of ensuring that the third party connections would integrate properly. This was followed on 5 July 2018 by a further email from LMG attaching links to its back-end software platform and stating, “We started back end for wallet, and you can access here…”.

There was considerable dispute between the parties as to precisely what was meant by this. It was put by Mr Bergin to Mrs Arlov and Mr Perković that LMG cannot have sent a completed product in July 2018 if they had only just started the back-end. He pointed further to (i) the Functional Specification Guides attached by LMG which stated that they were “Initial release” and (ii) LMG’s email of 14 September (referred to in paragraph 82 below) in which they referred to having “finished first version of Wallet”.

In response, both Mrs Arlov and Mr Perković were adamant that LMG had provided a complete platform with all the functionality required for the Genesis Wallet, even if some tweaking might have been required here and there. The fact, for example, that the attached Guide stated under the heading “Reports” that these were to be finalised with clients did not mean that the system had no reporting functionality, merely that LMG needed to know the format of the reports required in order to customise it.

Mr Perković stressed in particular that LMG must already have completed a functioning back-end system by July since the front-end sent on 14 June simply could not have functioned without a back-end. It is also noteworthy that the Release Date identified in one of the Functional Specification Guides was in fact February 2018. Mr Perković further said that if LMG had only started work on the back-office in July 2018, it would have been impossible for them to have completed the work by September. The author of the emails, Vlada Srdanović, was not a native English speaker and Mr Perković understood his choice of words to mean that the system was already functional but that LMG had just started work to effect a change in the currency exchange provider (Currency Cloud instead of Rietumu) and to integrate a new provider, Infobip, as requested by One Click. The integrations with Currency Cloud and Infobip were being undertaken with trial software prior to formal agreements being entered into by Digital Capital.

Mrs Arlov likewise insisted that the LMG system provided in July 2018 was fully functional even though some unwanted functionalities needed to be deleted and the branding changed to that of Digital Capital. However, these were only comparatively small changes which did not affect the functionality of the system.

I accept this evidence and reject the suggestion that no complete back-end system had been produced by LMG at this time. (Whether or not that system was “functional” in the sense of that it met all the contractual requirements is a different question as to which the experts were divided. This is discussed below.) I likewise accept Mrs Arlov’s evidence that if the Genesis front-end platform had been available at this time, tests could have been run with that instead of with the front-end provided by LMG.

On 24 July 2018, Mrs Arlov emailed Mr Brajković with a price list for the initial debit card order and an order form. She asked for the order form to be completed within the next two days in order to capture the production load. A response was received the same day from Mr Endriss who, not having previously met Mrs Arlov, introduced himself as the responsible manager for Genesis Wallet since 1 June who was working closely with Mr Brajković. Mrs Arlov replied to say that she would place the order as soon as the updated designs (which were required to meet new Mastercard rules and which she had been discussing with Barrage) had been received from Barrage. The design was eventually finalised on 27 July.

During the course of July and August, Digital Capital concluded further agreements with third party providers that were integrated into the core software. Although not required under the Agreement, it also changed the reporting functionality to comply with PSD2 as this was a regulatory obligation. Mrs Arlov said, and I accept, that none of this would have prevented integration with the Genesis platform had it been ready at that time.

On 3 September 2018, Mr Perković sent a text message to Mr Brajković stressing the importance of having Barrage’s technical requirements for integrating the two platforms. On 4 September 2018, Digital Capital provided Barrage with all the details required to integrate and test the payment gateway element of the core banking software, including a direct API and a web API. Mr Rimac replied the next day confirming that both APIs appeared to work and that Barrage would let Mrs Arlov know if anything else was needed. He expressed a desire to see encryption for certain emails and Mrs Arlov agreed to install the necessary programme.

On 14 September 2018, LMG sent another version of the software for review under cover of an email which read “We finished first version of Wallet and Wallet Back end, so you can review.” Consistently with my findings in paragraph 78 above, I reject the suggestion that LMG had not previously produced any finished version of the software. Rather I understand this email as meaning that LMG had incorporated the further refinements requested by Digital Capital since July. This would quite naturally be referred to as a completed first version but that does not imply that the core software did not previously exist in functional form and I so find. Mrs Arlov also forwarded this version to Digital Capital’s compliance officer, Mr Lewis, who indicated that there was a bit to add from his perspective but otherwise seemed delighted with the system.

An important meeting with Genesis then took place at Digital Capital’s offices in Split on 20 September 2018. This meeting was the subject of much controversy and I

Her contemporaneous note records that she first drew a schematic diagram on a board and then presented the different aspects of the system. Although Mr Dolić and Dr Krohn had previously seen a diagram at the meeting in November 2017, this was the first occasion on which Mr Streng was in attendance. In oral evidence Mrs Arlov explained that the meeting took place in a room with a projector and that she carried out the presentation from her laptop. She also referred to continuing problems with ABBA and her concern that it would not finish its system in time. ABBA had been granted an extension of time for delivery until 30 September and Digital Capital proposed to test the ABBA system. If it was not found to be satisfactory, then she suggested starting the integration with Digital Capital’s own system. The note records Mr Dolić and Dr Krohn agreeing with this suggestion.

The note also records Mr Kaiser asking Mrs Arlov what Digital Capital needed from Genesis. The answer was that it needed:

Also discussed was the Liechtenstein company to carry on the business which had now been incorporated and was currently opening bank accounts. Mrs Arlov indicated that Digital Capital would need all the company documentation for due diligence purposes and that they should think about transferring the Agreement from Genesis Iceland to the new company. Mr Kaiser suggested dealing with this through a WhatsApp group.

The question of shares in Digital Capital was raised again. Genesis indicated that they were interested in at least 50% of the shares and Mrs Arlov and Mr Perković indicated that they would need details and an offer first, suggesting again that it might be better to defer this discussion until after the system had gone live.

The note concludes by recording that Digital Capital would let Genesis know about the outcome with ABBA and that it was waiting for the specifications and all the data. I understand this to be a reference to the two points set out at paragraph 85 above.

This account of the meeting was challenged by the Defendant’s witnesses. Although none of them had taken any notes themselves, Dr Krohn nonetheless disputed the accuracy of Mrs Arlov’s note. In his written statement he said that Genesis had a different agenda at the meeting: namely, ensuring that Genesis had an ownership interest in Digital Capital and identifying what had happened to the money which

In cross-examination, however, it was plain that there was an element of confusion in Dr Krohn’s mind between this and a later meeting in March 2019. He could not remember the participants and I cannot therefore accept that he had any clear recollection of raising the points that he now claims were discussed. He did, however, recall some sort of presentation and status report on the project by Mrs Arlov. For his part, Mr Kaiser recalled some sort of presentation but not the detail. He said that he would have concentrated mainly on the financial side of the meeting.

As for Mr Dolić, his witness statement said nothing at all about what happened at the meeting, suggesting that he had no memory of it at all. In cross-examination, however, he claimed to “remember very vividly what happened and you didn’t show us anything meaningful”. I am sceptical of this sudden return of recollection, which to me smacks of ex post facto rationalisation.

I therefore reject the Defendant’s witnesses’ account of the meeting save where it is supported by Mrs Arlov’s note. Clearly there was discussion about the shareholding and Dr Krohn may well have enquired what expenses Digital Capital was incurring, but I am not satisfied that this was raised as a matter of extreme importance or urgency, or that any detailed request was made for financial information which Mrs Arlov promised to provide. It is noteworthy that Dr Krohn was not specific as to the nature of the information that was allegedly requested.

On 26 September 2018, LMG confirmed that the rebranding of the software to Digital Capital had been completed. Mrs Arlov explained that the reference in LMG’s email to “clean start” meant that all previous test transactions had been deleted.

On 29 September 2018, ABBA produced a test version of its software. According to Mrs Arlov’s note of a conversation she had with Mr Brajković on 4 October, ABBA had presented the system the previous day but been unable to show any functionality. Mr Rimac had asked Digital Capital to “whitelist” Barrage’s IP address so that Barrage could test the ABBA system for itself but Digital Capital was unable to do so as it was now in dispute with ABBA and no longer had access to its system. Mrs Arlov indicated that Digital Capital would therefore engage an independent expert to opine on the status of the ABBA system. She also queried why Barrage had not previously noticed the lack of functionality in the ABBA system and reiterated that Digital Capital needed Barrage’s technical specification urgently since integration would now be taking place with Digital Capital’s own system. However, Mr Brajković said that the Genesis platform had not been completed and that they were working on transferring to a different programming language. Again, Mrs Arlov was not cross-examined on this note and, in the absence of any contrary evidence from Mr Brajković, I have no reason not to accept it as accurate.

On 17 October 2018 a further telephone call took place between Mrs Arlov, Mr Perković, Mr Brajković and Mr Endriss. Mrs Arlov explained the situation with ABBA and said that Digital Capital was now proceeding with its own software. She offered

A call duly took place on 19 October 2018 with Mrs Arlov, Mr Perković, Mr Endriss and Dr Krohn. Mrs Arlov explained the situation with ABBA and the fact that since 4 October Digital Capital no longer had access to the ABBA system. She also expressed disappointment that Barrage had not previously picked up any problem. She confirmed that the Digital Capital system which had been presented in Split on 20 September was ready and recommended going ahead with that since it was pointless to continue with ABBA. Mrs Arlov again stated that Digital Capital was waiting for detailed technical specifications from the Genesis side so that integration could proceed smoothly. Her note records that Mr Endriss was working on this and agreed with the suggestion. She also informed Dr Krohn that the independent expert was finishing his testing of the ABBA system that day and that his report would be ready within two weeks whereupon she would send it to him.

Dr Krohn recalled being told by Mrs Arlov that the ABBA software had failed and that he asked for proof. He said in his written statement that by this time he was beginning to lose faith in the ability of Digital Capital to deliver the project. Given, however, that he was on his own admission not involved in the technical side of the project, and given the lack of any previous complaints, it is difficult to see any rational basis for this conclusion.

In the event, the report was sent to Dr Krohn on 30 October 2018. Mrs Arlov’s assessment was that the ABBA system was partial, incomplete and non-functional and that further co-operation with ABBA should be halted. She yet again stressed the urgent need for a technical specification of what the Genesis Wallet would require from Digital Capital in order to implement the alternative Digital Capital solution. However, on his own admission, Dr Krohn did nothing with the email and thinks he probably just archived it.

Around this time, it was discovered that a Chinese partner in Genesis Mining Hong Kong had diverted some 700,000 of the company’s graphic cards and 100,000 mining rigs to his own use. The damage to Genesis Mining in terms of lost profits ran to tens of millions, although Dr Krohn pointed out that this represented opportunity losses rather than direct financial losses, which were minimal. I have no reason to disbelieve him in this respect.

Around this time, Mr Dolić happened to be in Hong Kong at the same time as Mr Streng. He heard about Genesis’ financial problems and suggested that they meet. Mr Dolić was also by now aware from talking to Mr Brajković of Barrage that the

On 19 November 2018, Mr Perković received a message from Mr Dolić via the Telegram messaging service. In it, Mr Dolić said that he had been asked by Mr Streng to contact Mr Perković to say that Genesis Iceland could no longer support the monthly costs of the Agreement and was being forced to cut its expenses on all projects. He explained about the situation in China and said that the situation was not an easy one for them. Mr Dolić also said that Dr Krohn and Mr Streng would accept an option to sell the e-money institution (i.e. Digital Capital) to cover the costs. He asked whether Mr Perković had any suggestions on how to proceed.

It is relevant to note at this stage that the market in bitcoin had fallen dramatically – by about 75%. Mr Kaiser described the period from 2017 through 2018 as possibly the worst market conditions for cryptocurrency that had ever been experienced. This, combined with the Chinese problem (which undoubtedly had a dramatic effect on anticipated revenues) meant that Genesis was facing a difficult financial situation. Dr Krohn admitted that some employees were let go at around this time, albeit that the group was ultimately able to weather the storm successfully.

In his oral evidence, Mr Dolić said that one of his main reasons for making contact with Mr Perković was his awareness of the difficulties in the relationship between Digital Capital and Genesis Iceland and his desire to try to mediate as he still regarded Mr Perković as a trusted friend. However, when asked whether what he had said in his message was true, namely that Genesis needed to cut costs across all its projects for financial reasons, he was very difficult to pin down. Initially he suggested that Genesis simply wanted to axe the project but that he did not say so directly because he did not want to make Mr Perković feel bad. Next came a suggestion that it had already been decided not to proceed because Genesis had not seen any outcome from Digital Capital. Pressed on this, he claimed that it was nothing to do with him anyway since he had already left the company, and that he could not even say whether what he had said to Mr Perković was true. Finally, he stated that the decision to end the collaboration with Digital Capital was not taken until after he left in December 2018.

This is very unsatisfactory. Whatever may have been going on internally on the Genesis side (and I bear in mind that I have not heard evidence from Mr Streng and that no internal board minutes or notes have been disclosed relating to this time period), there is no indication in any of the documents before me to suggest that Genesis was unhappy in any way with the services that Digital Capital had hitherto provided and was continuing to provide, or that it wished to withdraw from the project for that reason. As I have said in paragraph 32 above, the Defendant’s witnesses all spoke to having had increasingly grave doubts since at least September 2018 about Digital Capital’s ability to deliver on its commitments and to being dismayed by its continuing failure to respond to reasonable requests for information. The problem is that there is no trace whatsoever of such concerns or requests on any of the contemporaneous documents. It therefore seems to me that the recollection of the Defendant’s witnesses has become coloured by their understandable desire to support the Defendant’s case and that they have convinced themselves that complaints which only surfaced at a later date were in fact being voiced earlier.

I accordingly find that the financial difficulties facing the Genesis group was the primary motivation for Mr Dolić’s message and that it was for this reason that from this date onwards, Genesis Iceland stopped paying Digital Capital’s monthly invoices.

During the course of the hearing both the Claimant and the Defendant made late disclosure of, on the one hand, messages exchanged between Mr Dolić and Mr Perković and, on the other, WhatsApp group messages provided by Mr Kaiser. These cast a materially different light on the exchanges which took place around this time and raised further doubts in my mind about the reliability of the Defendant’s evidence. Beyond expressing regret that these documents were not produced during the disclosure process, not least because it necessitated the recall of Mr Dolić, I say nothing further about their late emergence. However, they did have the effect of seriously undermining the credibility of what was said by Dr Krohn and Mr Kaiser about these exchanges in their witness statements. It is one thing to have no recollection and to have forgotten about the existence of documents which might have prompted a recollection. It is quite another to set out an ostensibly clear recollection which is at odds with documents which (in the case of the WhatsApp messages at least) should have been available to them.

On 21 November 2018, Mr Dolić messaged Mr Perković to ask whether he could meet Dr Krohn in Osijek on 26 November. It would appear that some potential investors, including one called Chakrit, were very interested in participating in the Genesis Wallet project and either buying shares in Digital Capital or helping with technological development. Mr Perković suggested that he and Mrs Arlov could meet Dr Krohn in Zagreb before he left for Osijek as they had other business there from 26-28 November. (They were in fact attending a Shift Money conference there.)

Mr Dolić replied on 23 November saying that he was talking at that moment to Dr Krohn and Mr Streng and that they needed a complete picture of Digital Capital’s status in order to talk to Chakrit and other potential investors about specifics. He asked whether Mr Perković would agree to create a group to “audit” the current Digital Capital status as a base for future steps. As there were many topics to discuss, he suggested meeting in Munich to agree on specific steps. Mr Perković was agreeable to this and it was arranged that Dr Krohn would come to Munich for a meeting on 5 December. Mr Dolić stated that Dr Krohn “wants you to send financial reports (I’m not sure it it’s even possible) Nico requested or will request today.” Mr Perković’s response to this was that they would consider the requirements during the meeting to determine what was appropriate. It was agreed that they would meet Mr Dolić on 4 December before having a group meeting the following day.

On 27 November 2018 at 8.37 pm, Mr Kaiser emailed Mrs Arlov copying also Dr Krohn and Mr Streng. He referred to the meeting in Split and continued “Since already a couple of months passed since then, I would like to request the following data from your side:…” The requested data included Digital Capital’s latest financial statements, bank statements to give an indication of cashflows, an inventory of assets, costs structure, headcount, payroll data and details of monthly payments to external service providers. He also asked for proof of the services provided under the Agreement, namely software and system set-up, maintenance records and test protocols.

The overwhelming inference is that this was the email which Mr Dolić had told Mr Perković to expect and that it was primarily directed at eliciting information for the

It is clear that Mr Perković then had a telephone conversation with Mr Dolić on 28 November. The gist of that call was relayed by Mr Dolić to Dr Krohn in the WhatsApp group messages disclosed belatedly by Mr Kaiser. It is noteworthy that both Dr Krohn and Mr Kaiser were insistent in their written statements that it had been Mrs Arlov who spoke to Mr Dolić following receipt of the email. While the mistake was corrected before they gave oral evidence, it did nothing to bolster their general credibility in my eyes, particularly since the WhatsApp messages were obviously documents which should have been identified and disclosed at the outset.

Mr Perković did not accept that the summary in Mr Dolić’s WhatsApp message reflected precisely what he had said in all respects but, allowing for the fact that Mr Dolić would necessarily have been putting his own interpretation on what was said, I am satisfied that it is broadly accurate. Thus, Mr Perković stressed that Digital Capital as an EMI was a legally independent entity which was responsible to its regulators. He also indicated his view that any potential investor should send an official declaration of intent and sign a non-disclosure agreement, following which an audit of Digital Capital could be carried out at any time by a recognised body such as KPMG or PWC.

More contentious was the part of Mr Dolić’s message which read “From Nico we would expect that he would send a further email which says that the first email was addressed to another company and thus incorrectly sent to DC.” Mr Perković did not accept that he had asked for an email in these terms. His recollection was rather that he wanted the procedure outlined above to be followed (declaration of intent, followed by non- disclosure agreement) and that Mr Kaiser should therefore clarify the reasons for sending the email, namely that the information was required for the investors and the nature of the interest being expressed.

Mr Perković also quibbled with the part of Mr Dolić’s message which recorded him as saying that he could not send the data requested by Mr Kaiser to someone who had no legal entitlement to it, but that he would show it to Mr Dolić, Dr Krohn and Mr Streng during a personal discussion. While he accepted having said that a company with regulatory obligations could only share information in conformity with proper procedures, he said that he would never have agreed to show Digital Capital’s information to anyone as only Mrs Arlov could do this. I nonetheless conclude that he must have said something to indicate that the information might be forthcoming on an informal basis.

Mr Kaiser did indeed send a further email to Mrs Arlov apologising for having “mixed up the wrong person/company to receive this e-mail”. I infer from this that Genesis accepted the force of the point made by Mr Perković that Digital Capital should only be seen to be giving financial information to someone who had a legal right to obtain it.

It was a major plank in the Defendant’s factual case that one of the reasons for its loss of confidence in Digital Capital was the repeated failure since September 2018 to respond to requests for financial information. Like Dr Krohn, Mr Kaiser insisted in his written statement that Genesis was becoming increasingly disturbed by Digital Capital’s failure to disclose financial information which had been requested at the 20 September meeting and that the only reason for sending his email of 27 November was to chase it up as part of his own due diligence. Part-way through his cross-examination, however, the messages referred to above were disclosed which cast a different light on the purpose and intent of the email. Faced with this, Mr Kaiser changed tack and maintained that the email had had a dual purpose: on the one hand to obtain information for the potential investors, but on the other also for Genesis’ own purposes.

He was pressed by Mrs Arlov as to the basis on which Genesis Iceland as a client would have been entitled to any of information requested other than that which was already in the public domain, such as published accounts. His initial reaction was to claim that he was representing Dr Krohn as CEO of Genesis Iceland. Then he said that Dr Krohn was a shareholder and was entitled to the information in that capacity. When pressed further, he said that he had in fact requested the information at the 20 September meeting both as a representative of Genesis Iceland and as a representative for Dr Krohn personally.

I am unable to accept this explanation which I find wholly implausible. As I have indicated above, while I am satisfied that the shareholdings in Digital Capital were raised at the meeting on 20 September I am not satisfied that it was discussed in any depth, nor that there was any request for the detailed information set out in Mr Kaiser’s 27 November email, the latter being prompted by the expression of interest from the investors. Had Genesis had genuine concerns that Digital Capital was withholding important information which it had agreed on 20 September to provide, I have no doubt that it would not have waited two months before following it up. It is noteworthy that the Agreement itself contains extensive audit rights, but that Genesis Iceland never sought to exercise those rights, nor did Mr Kaiser ever seek to check what entitlement either Genesis Iceland or Dr Krohn had to the financial information sought.

In any event, the suggestion that Digital Capital was reluctant to disclose the information is wholly belied by the WhatsApp group messages. Not only does Mr Dolić record Mr Perković as having volunteered to have an audit conducted by an internationally recognised firm of accountants, but the impression was clearly given to Mr Dolić that the information might be made available informally. It is true that Mr Perković and Mrs Arlov sought at the 8 May and 20 September meetings to postpone further discussion of the shareholdings in Digital Capital until after the Genesis Wallet had gone live. However, I have no doubt that they did not at that stage envisage the delays which later transpired and that this was not an attempt by them to prevaricate.

Mrs Arlov was cross-examined at some length as to why she did not respond to Mr Kaiser’s initial email of 27 November. She said in her statement that she never had a chance to do so because it was overtaken by the retraction. In her oral evidence (given before the disclosure of the further messages) she explained that she had been at an event at the time and was not monitoring her emails. She could not remember exactly when she first saw the initial email but recalled seeing the retraction first because of the way her inbox is configured.

I accept that Mrs Arlov may not have seen the email until the following morning. The messages exchanged between Mr Perković and Mr Dolić confirm that Mrs Arlov had been at the Shift Money conference (they attached pictures of the Digital Capital stand at the event). However, I cannot accept that she did not see the email prior to its retraction since the retraction was only sent following Mr Perković’s call to Mr Dolić and Mr Perković was quite clear that he had not received the email directly and that it was shown to him by Mrs Arlov. I therefore find that she saw it sometime around 0830 in the morning and showed it to Mr Perković, prompting him to call Mr Dolić at 0841.

Nonetheless, given the need to preserve the independence of Digital Capital from Genesis, and the fact that the retraction would have arrived within hours of her seeing the email and showing it to Mr Perković, I find it understandable that she did not regard it as either necessary or appropriate to reply.

This sequence of events also makes sense of an exchange of messages on 29 November 2018 between Mrs Arlov and Dr Krohn. In it, Dr Krohn apologises “for yesterday” and asks which of the requested information she can provide in the next few days. Mrs Arlov’s reply was she would do her best to prepare a presentation showing Digital Capital’s business achievements. I accept that this was probably a reference back to the information requested in Mr Kaiser’s 27 November email but that it was raised by Dr Krohn in the context of the information required for potential investors. Importantly Mrs Arlov also said that she would prepare a presentation of all the software solutions

On 4/5 December 2018, the meetings agreed between Mr Perković and Mr Dolić took place in Munich. As arranged, Mrs Arlov, Mr Perković and Mr Dolić met on 4 December for lunch. Mr Dolić informed them that the situation was very difficult and that Genesis would probably have to let the entire Munich office go. He referred to the problem with the Chinese partner and the fall in the price of cryptocurrency. This had led to problems with payouts to mining customers which he would probably have to meet out of his own pocket. Mr Dolić said that he would love to keep the Digital Capital project going and Mrs Arlov said that they would present the whole system to him and Dr Krohn the next day. They would see what could be done and Digital Capital would wait until Genesis had recovered. Mr Dolić also asked if Digital Capital could arrange a meeting room for 5 December since the atmosphere in the Genesis offices was apparently so bad.

Digital Capital organised a room as requested at the Charles Hotel and even arranged for two interpreters to be present, expecting representatives of Genesis’ technical team to attend as well. But, unfortunately, Dr Krohn was ill and could not be present, there were no technical representatives on behalf of Genesis and only Mr Dolić appeared. Mrs Arlov’s note records that she showed Mr Dolić the specifications of the Digital Capital system, including planned upgrades which were not covered by the Agreement. She then presented the entire software and mentioned that Digital Capital was

The note also records that a “Financial Issue” was raised. I infer that this was a reference to the non-payment of Digital Capital’s most recent invoices, since Mr Dolić is recorded as having asked whether Digital Capital could wait a couple of months until the financial situation of Genesis had stabilised. He said that the project was very important to them. Mr Perković indicated that Digital Capital could wait for a couple of months but that the invoices would then have to be paid. Meanwhile, Digital Capital would continue to maintain the entire system. Mr Dolić agreed to this and said that he would inform Dr Krohn and Mr Streng. There was then a discussion about other possibilities. Mr Dolić said that he would talk to various investors and Mr Perković said that they were open to all options.

Mr Dolić challenged this account of the meetings in his oral evidence. However, he clearly could not remember very much about either the lunch on 4 December or the meeting on 5 December. His complete lack of independent recollection is demonstrated by the fact that his written statement was confined to a denial that he had ever “approved” any system presented by Digital Capital. This was on the grounds, not of any positive recollection, but on the basis that he would not have had authority to do so. However, it was never suggested by Digital Capital that he had given formal approval on behalf of Genesis Iceland. Moreover, his statement does not deny that anything was presented; he merely states that he did not recall ever having seen anything “meaningful”.

On 8 December 2018 a call took place between Mrs Arlov, Mr Perković, Mr Dolić, Mr Brajković and one other person. Most of the discussion related to the problems with ABBA but Mr Perković raised again the question of the technical specifications requested from Barrage. Mr Brajković should have been working on it but everything was now in question due to Genesis’ financial situation. Mr Dolić repeated that he would press for the continuation of the project but asked Digital Capital to wait as had been agreed at the meeting in Munich and this was confirmed.

On 20 December 2018, Mr Dolić formally resigned from the board of Genesis Iceland.

On 28 January 2019 an internal discussion took place by Skype between Mr Dolić, Dr Krohn and Mr Bjoern Arzt who was the General Counsel of the Genesis group. In his oral evidence, Mr Dolić initially denied that he had expressed any opinion or given any advice to Genesis about the project after he left the company. Confronted with the evidence of this meeting, he was forced to retract that denial. The minutes of the discussion record that Mr Dolić outlined the history of Digital Capital. Contrary to the impression he had given to Digital Capital in December as recorded by Mrs Arlov in her notes, the minutes of this meeting suggest that he now took a pessimistic view, considering that the current management of Digital Capital would not be able to finalise the project successfully. He had apparently talked about this to Mr Perković and discussed the valuation of the company, as to which his own valuation (€2 million) was substantially less than Mr Perković’s estimate (€7 million). Mr Dolić said that Mrs

The minutes record an agreement that the management of Digital Capital should be replaced and measures taken to ensure that the remaining liquidity was not used or abused by Digital Capital. Mr Dolić undertook to stand behind the liabilities of Digital Capital. It was also agreed that Dr Krohn should meet Mrs Arlov and Mr Perković in person to continue the dialogue.

A few days later on 7 February 2019, a management call took place between Dr Krohn and Mr Streng as shareholders and Mr Kaiser and someone described as “rh” which I take to be a reference to a Rene Hennen who appears elsewhere in the documents. I am not aware of the role played by Mr Hennen. A number of matters were discussed, including Barrage and the Genesis Wallet project. It appears from other parts of the note that Genesis was in a somewhat unsettled state and looking to cut costs wherever possible, including in respect of the fees payable to Barrage. I note a reference to Genesis Mining needing more cash and a proposal to proceed with the sale of shares. In his oral evidence, Mr Ivanšić confirmed that Barrage optimised the crypto platform around this time so as to reduce costs by redoing some parts of the database and cutting some server costs.

So far as the Genesis Wallet project specifically was concerned, the question raised for consideration was the amount of financing that would be required from Genesis and how much Barrage could contribute to finance the project, possibly in exchange for shares. A reference was also made to talking to Chakrit and someone called Abdumalik about potential investment after the discussions with Barrage had been concluded. It was estimated that the project was currently costing €200,000 per month and that some

A further management call took place on 19 February 2019. The minutes of this call are identical in some places to those of the 7 February call. I infer that this is because they effectively updated the previous minutes. However, they additionally included a note recording the shareholding in Digital Capital and referred to suing Digital Capital for non-fulfilment of the Agreement. It is unclear to me whether this was an actual decision or a topic for discussion. Given the subsequent meeting which took place with Digital Capital in March, I am inclined to think it was the latter.

On 22 March 2019, a meeting took place with Barrage at its new offices in Osijek. Dr Krohn, Mr Streng, Mr Kaiser, Mr Endriss and Mr Hennen attended on behalf of Genesis. Mr Ivanšić and Mr Rimac represented Barrage with two other colleagues. The purpose of the meeting appears to have been specifically to discuss the possibility of Barrage assuming responsibility for the ongoing development of the Genesis Wallet. Dr Krohn said that by this date Genesis was becoming less interested in the project and that Barrage was more of the driving force and had better insight into it. The note records a proposal that Barrage’s existing 10% shareholding in the Liechtenstein company should be increased to 51% in return for Barrage assuming the costs of obtaining an EML and development costs up to September 2019. At that point, the costs would either be shared equally or an outside investor would be brought in. Mr

It was put to Dr Krohn that this meeting was evidence that Genesis was looking to replace Digital Capital with Barrage in breach of the exclusivity provisions in the Agreement. He denied that there was any settled decision to dispense with Digital Capital’s services. His evidence was that it was becoming increasingly likely that Digital Capital would not be able to deliver and that they therefore needed to consider a back-up solution but that if Digital Capital did provide what was required, they would have been happy to take that. Both he and Mr Ivanšić confirmed that no agreement was ever concluded with Barrage. No breach of the exclusivity clause can therefore have occurred. Mr Kaiser’s evidence was to much the same effect.

Two days later an important meeting took place with Digital Capital. This appears to have been the first contact between the parties since 8 December 2018, some four months previously. Mrs Arlov and Mr Perković were present together with Dr Krohn and Mr Kaiser. Mr Arzt participated by telephone. Notes of the meeting were taken by both Mrs Arlov and Mr Kaiser.

At the outset of the hearing an application was made by Mr Bergin to adduce a partial transcript of a recording of the meeting which Mr Arzt had made on his phone. This had apparently been provided to the Defendant’s solicitors but overlooked for some reason and was not rediscovered until 28 June 2021. A transcript of those parts of the meeting which had been conducted in English was then obtained and both the recording and the transcript were disclosed to the Claimant on 1 July. Because of the failure to disclose, Mr Bergin also applied for relief from sanctions. I refused the application for essentially three reasons: (i) Mr Kaiser’s note had in any event been compiled on the basis of the transcription and it was therefore unclear to me quite what the transcript could be expected to add; (ii) only the English dialogue had been translated and transcribed in circumstances where a significant part of the discussion had taken place in Croatian and German; (iii) the very late disclosure had not given Mrs Arlov a proper opportunity to listen to the recording herself either to verify the English translation or to obtain a translation of the parts in Croatian and German. Given that Mr Perković only speaks Croatian and that the disputed part of the meeting centred on what he said, it seemed to me that it would be impossible for me to derive any benefit from effectively one side of a conversation. No excuse was (rightly) offered for the late disclosure and in all the circumstances, it did not seem to me that the interests of justice required relief from sanctions to be granted.

I start with Mr Kaiser’s note which he stated had been compiled a couple of days after the meeting. I note in particular the opening section which sets out under a heading “Preliminary remark” a statement of the Genesis strategy for the meeting which I set out in full:

I regard this section of Mr Kaiser’s minutes as referring to an internal Genesis understanding rather than as anything which was communicated to Digital Capital in terms. But it clearly demonstrates the tone that Genesis had decided to adopt in the meeting and to that extent informs the way in which the ensuing discussion is to be understood. I am in no doubt that Genesis Iceland had formed the view at this stage that it could no longer afford to continue financing the project without external funding and that an agreement had been reached at least in principle with Barrage to bear the costs of the project until September. I also accept that Genesis would need to find another partner for the FIAT part of the system if Digital Capital was unable to perform its part of the Agreement and that it was therefore important for Genesis to ascertain the status of Digital Capital’s core banking system.

The salient points to emerge from the remainder of Mr Kaiser’s note for present purposes are as follows:

Mrs Arlov’s note was much shorter than Mr Kaiser’s minutes. This was necessarily so, since she was having to translate throughout for Mr Perković. Nonetheless, the points that I have extracted from Mr Kaiser’s minutes are largely reflected in her note. In particular, she records that:

Mrs Arlov’s note also mentioned that Genesis had been working on transferring their platform to a new programming language. This does not feature in Mr Kaiser’s note but had been mentioned by Mr Brajković in his conversation with Mrs Arlov on 29 September 2018 and was also confirmed by Mr Ivanšić in his oral evidence. She also recorded Digital Capital’s agreement to allow until 30 June 2019 for payment of Digital Capital’s outstanding invoices and Dr Krohn’s confirmation that they would be paid by then. This likewise does not feature in Mr Kaiser’s note. He refers instead to the possibility that Digital Capital would be put into hibernation at the end of June. Mrs Arlov denied that this was ever a definite decision and, given the context in which the note appears, I am satisfied that it was only to happen if no investment was secured which would allow Digital Capital’s invoices to be paid so that it could maintain the necessary cash balance. There is therefore no inconsistency between this and Mrs Arlov’s evidence that Digital Capital was prepared to wait for payment until the end of June, Dr Krohn having confirmed that they would have found an investor by then.

During Mr Bergin’s cross-examination of Mrs Arlov, it also emerged that the parties were at odds as to what was meant by the phrase “trial version” in Mr Kaiser’s note. Mr Bergin suggested that this meant that the core banking system had not in fact been completed by that date; Mrs Arlov and Mr Perković were insistent that this was not the case and that Mr Perković had confirmed at the meeting that the core banking system

I also find that the Genesis representatives expressed no dissatisfaction with Digital Capital’s services to date. On the contrary the overwhelming impression created at this meeting (in line with the Genesis strategy) was one of positivity and a desire to press ahead together with the project. I reject the suggestion repeatedly made by all of the Defendant’s witnesses that Digital Capital was reluctant to disclose financial information. On the contrary, answers to many of the questions raised in Mr Kaiser’s email of 27 November 2018 were provided at the meeting as he records himself, and I note, in particular, that the provision of further information was not included in his list of next steps/timeline as I would have expected if this had been a truly serious issue.

That said, I do accept that the question of the shareholding in Digital Capital was a topic which Genesis had been raising repeatedly since 8 May 2018. In this respect, it is easy to see the competing tensions at play. On the one hand it does not appear ever to have been disputed by Digital Capital that there was at least an informal agreement that shares would be transferred to Genesis once the Genesis Wallet project was up and running. On the other hand, the project had been delayed and Digital Capital was incurring on-going development and maintenance costs (which Genesis ceased to pay in October 2018). I can therefore see every commercial reason why Mrs Arlov and Mr Perković were reluctant for Mrs Arlov and Mr Bruno Perković to relinquish their shareholdings until at least Digital Capital’s outstanding invoices were paid. In some ways, this was the only bargaining chip they had at their disposal. Contrary to the picture which the Genesis witnesses sought to paint, I do not regard this as indicative of bad faith or underhand dealing; it was simply a negotiating position.

The documentary evidence does not disclose that there was any further communication between the parties following the meeting of 24 March 2019 until 3 June 2019. Mr Kaiser said that he definitely discussed the meeting with Mr Endriss. He also said that he chased Mrs Arlov twice after the meeting but received no response. However, no written communications were produced to support this assertion.

On 3 June 2019, Digital Capital received a Pre-Action Protocol Letter of Claim from Genesis Iceland’s solicitors, Charles Fussell & Co., claiming that Digital Capital had substantially failed to provide the services contracted for under the Agreement and that Genesis had not been provided with evidence of any work undertaken/benefits rendered by Digital Capital under the Agreement. The letter expressed concern that sums paid to Digital Capital by Genesis Iceland had been misapplied and claimed that there had been a total failure of consideration. Charles Fussell further asserted that Digital Capital had thereby committed material breaches of the Agreement which were incapable of remedy and so entitled Genesis Iceland to terminate the Agreement immediately. Alternatively, it was said that Digital Capital was in repudiatory breach which Genesis Iceland accepted.

On 1 July 2019, Digital Capital served a notice of suspension on Genesis Iceland under clause 13 of the Agreement on the basis that its outstanding invoices had not been paid.

The substantive allegations made by Genesis Iceland were denied in full by Digital Capital which maintained that it had performed all its obligations under the Agreement. Indeed, it was subsequently accepted by Charles Fussell that at least some work had been carried out under the Agreement rather than none at all, as previously suggested. Nonetheless, in a letter dated 11 September 2019, the Defendant’s position was substantially maintained, namely that Digital Capital had failed to provide the system required by the Agreement and was either unwilling or unable to do so. Accordingly, the Defendant was under no obligation to pay any further fees and was indeed entitled to seek reimbursement of fees already paid.

A Claim Form and Particulars of Claim were served by Digital Capital on 30 September 2019 asserting that the stance adopted by Genesis Iceland itself amounted to a repudiatory breach of the Agreement and purporting to accept that repudiation. This was confirmed in a letter from its solicitors, Davis Woolfe, dated 1 October 2019.

It is difficult to know quite why the relationship between Digital Capital and Genesis broke down in the way that it did. The Defendant’s witnesses claimed that it was because Digital Capital had failed to deliver anything which could be used for the project and that Genesis had lost confidence in its ability to do so.

However, I find it difficult to accept that this can have been the only reason. As appears from the factual narrative set out above, there was never at any stage any expression of dissatisfaction with what Digital Capital had provided or were planning to provide. It is true that there had been delays, but these were on both sides and the impression given by Genesis at the 24 March 2019 meeting was that it wished to press ahead albeit that outside investment would be needed.

Moreover, I can discern no reasonable basis on which any of the witnesses who gave evidence for Genesis before me could have concluded that Digital Capital had failed to provide anything of value. None of them was technically qualified to express such an opinion. Mr Brajković might have been able to do so but (i) he was not called and (ii) according to Mr Ivanšić, he was neither a software developer nor involved on a daily basis in any event. Mr Ivanšić’s own expertise was limited to design, not software and his written statement suggested that he had no first-hand knowledge of the capabilities of the Digital Capital system. His opinion was based upon what he was told by others. Furthermore, it does not seem that anyone from Genesis or Barrage had ever examined or evaluated the Digital Capital system in its entirety.

It is possible that Dr Krohn was more concerned by the collapse of the ABBA option than was warranted, having not completely understood that Digital Capital had its own alternative solution. However, it seems to me more likely that Genesis decided to withdraw from the entire project during the course of 2019 for a combination of reasons. First, it was apparent from late 2018 that it could no longer afford to fund the project itself and finding external investors was proving difficult. Secondly, the crypto platform was also subject to delays. The evidence left me in a state of complete ignorance as to what was happening with it during 2019 save for the undoubted fact that it never went live. Mr Dolić said that it was complete in 2017 but I suspect his

Thirdly, these delays meant that Genesis had all but lost the valuable advantage of being the first into the market with this kind of system. Fourthly, it was faced with the prospect of having either to pay Digital Capital outstanding invoices at the end of June 2019 or being sued.

In those circumstances, Genesis had every incentive to try to extricate the Defendant from the Agreement without having to make any further payment to Digital Capital. The letter from Charles Fussell & Co. can therefore readily be understood as a pre- emptive strike.

However, it is unnecessary for me to make any findings on this point. If the Defendant was legally entitled to terminate the Agreement when it did, its motivation for so doing is irrelevant and to that question I now turn.

On 15 May 2020, a hearing for directions took place before Teare J. He approved the List of Issues and ordered that there should be a split trial with the first trial determining all issues, save for each party’s claim for damages. This is the first trial contemplated by Teare J’s directions.

Following Mr Bergin’s indication that the Defendant no longer pursued a claim in restitution, the issues remaining for the court’s determination are as follows:

I propose to address these issues in a slightly different manner way from that in which they are currently formulated.

Implied terms

Little needs to be said under this heading. The Defendant’s formally pleaded case was that the Agreement contained an implied term that if Digital Capital failed to achieve Go Live by 10 July 2018, it would no longer be entitled to charge the Defendant for operational fees or system maintenance, there being by definition no system either to

This was never a promising argument and in the face of clause 30.2 of the Agreement it seemed to me to be all but unarguable. In the event, Mr Bergin (rightly, in my opinion) did not seek to dissuade me from the view that clause 30.2 meant exactly what it said and was effective to exclude all common law implied terms.

Was the Defendant entitled to terminate the Agreement on 3 June 2019?

Contractual vs common law right to repudiate

The question whether Genesis Iceland was entitled to terminate the Agreement as it purported to do on 3 June 2019 lies at the heart of this case. In order to answer that question, however, it is necessary to address an anterior question of construction as to the relationship between the contractual right of termination provided in clause 16.1 of the Agreement and the common right to terminate for repudiatory breach.

Clause 16.1 provides that:

It was common ground between the parties that all the breaches relied upon by the Defendant were material and that that they were all in principle remediable. They were therefore within the scope of clause 16.1. Mr Bergin, however, founded the Defendant’s case squarely on a common law right to terminate. His argument was that Digital Capital’s breaches, while material, were more than merely material and in fact were so serious as to be repudiatory. Thus, the Defendant had an independent right to terminate at common law which was not circumscribed by clause 16.1 and its requirement to give notice.

If he was wrong about that, it was not in dispute that no notice was ever given and that Digital Capital’s claim must therefore succeed, irrespective of any finding as to whether or not the alleged breaches were material, repudiatory or neither, or whether they could or could not have been remedied within 30 days. (As to this, Dr Kovačević said that they all could have been remedied within 30 days; Dr Hunt said that, although possible, probably not all of them could.⁴)

The relationship between contractual and common law rights to terminate was considered by the Court of Appeal in the case of Stocznia Gdynia SA v Gearbulk Holdings Ltd, [2009] EWCA Civ 75; [2009] 1 Lloyd’s Rep. 461. That was a

The leading judgment was given by Moore-Bick LJ in which he commented as follows:

What emerges clearly from these passages is that the relationship between contractual and common law rights of termination is a question of construction in each individual case. No hard and fast rules can be laid down.

In the context of the present case, the Defendant’s common law right to terminate will have arisen if either Digital Capital was in breach of condition or serious breach of an innominate term going to the root of the contract, or if it renounced the Agreement by evincing an intention no longer to be bound by its terms. However, in evaluating whether Digital Capital committed a breach of the requisite seriousness or evinced a renunciatory intention, it is necessary to take account of the way in which the parties have contractually agreed to treat certain types of breach: BskyB Ltd v HP Enterprise Services UK Ltd, [2010] EWHC 86 (TCC) at [1363], [1366].

Clause 16.1 is clearly capable of applying to all breaches from “material” upwards on the scale of seriousness. A repudiatory breach is necessarily material – a proposition from which Mr Bergin did not dissent. However, the converse is not always true since not all material breaches are necessarily repudiatory. There was no real dispute in this case that the parties had agreed that a material but non-repudiatory breach should (if remediable) not give rise to a right to terminate unless the guilty party had failed to remedy it within 30 days. Conversely, a failure to remedy within 30 days what would otherwise not be a repudiatory breach was contractually deemed to be repudiatory in and of itself. There was likewise no dispute that that the contractual right of termination (and its concomitant obligation to give notice) only applied to breaches falling within the scope of clause 16.1. How, then, does the clause apply to breaches which are independently repudiatory?

So far as its wording goes, the clause is on its face capable of applying to any type of material breach, whether repudiatory or not. It is not expressly limited to non- repudiatory material breaches. Had it been a question of considering clause 16.1 in isolation, it would have been distinctly arguable that the parties had agreed that all material breaches, whether otherwise repudiatory or not, would only be treated as repudiatory for the purposes of the Agreement if they were not (where remediable) remedied within 30 days. Construed in this way the clause would not exclude the common law right but merely define the type of conduct which would give rise to it, thereby permitting the innocent party to claim damages for repudiation in addition to any contractual remedy. I regard Vinergy International (PVT) Ltd v Richmond Mercantile Ltd FZC, [2016] EWHC 525 (Comm) as distinguishable in this respect since the termination clause in issue there, unlike clause 16.1, applied to any breach from most trivial to the most serious.

Nonetheless, looking at the contract as a whole, I conclude that it is not open to Digital Capital to argue that clause 16.1 should be construed as similarly defining and circumscribing the common law right in this way. This is because of clause 16.5 which expressly preserves “any other right or remedy of either party in respect of the breach concerned” (emphasis added). Not only does this have the effect of preserving any common law remedy, it also preserves any other right that the Defendant may independently have at common law in respect of material breaches falling within clause 16.1.

I therefore accept Mr Bergin’s submission that, if Digital Capital had committed breaches of contract which were independently repudiatory otherwise than by virtue of simply being material, then the Defendant was entitled to bypass clause 16.1 altogether and exercise its common law right to terminate for repudiatory breach.

Repudiatory breach

The question is therefore whether Digital Capital was in repudiatory breach of the Agreement as opposed to simply being in material breach. There was no overt renunciation of the Agreement and Mr Bergin must therefore establish either that Digital Capital evinced an intention by its conduct no longer to perform, whether through unwillingness or inability, or that it was in serious breach going to the root of the contract. His primary case in this respect rested on an alleged failure by Digital Capital to deliver any software system with the required functionality within a reasonable time. In the alternative, he relied as a fallback position on Digital Capital’s continuing failure to supply financial information or proof of the state of development of its system in response to Genesis’ requests.

I consider each of these in turn.

Both parties agreed that the case was essentially very simple, the key issue being whether the Claimant had complied with its obligations under the Agreement. This issue in turn had two aspects, one technical and one factual. The technical aspect, addressed primarily by the experts, was whether the Claimant was at any time able to deliver to the Defendant a functioning system. The factual aspect was whether it was only prevented from so doing because of the Defendant’s failure to supply the technical specification required for integration of the Claimant’s software with the Defendant’s front-end system.

The technical case was addressed by the two expert witnesses. In cross examination, Mr Bergin sought to suggest that Dr Kovačević had little or no experience of software development. However, this was not true: Dr Kovačević had been the team leader responsible for developing new financial and accounting software while he was at the Institute for Public Health. In my view both experts were eminently well-qualified to express an opinion on the matters at hand.

It was also suggested that Dr Kovačević’s independence was compromised by his failure to disclose that he had inspected the ABBA system as a court-appointed expert in 2019 in litigation between Digital Capital and ABBA. However, Dr Kovačević’s report on the ABBA system was in the trial bundle and his involvement was patent on

In truth, any perceived lack of cooperation on the part of Dr Kovačević probably stemmed from the fact that the experts were like ships passing in the night, mainly due to an inherent ambiguity in the question which they were asked to consider. This was “whether the Claimant was at any time able to deliver to the Defendant a functioning system” but whatever the perceived merits of this question at the time it was formulated, it was apparent by the end of the argument that it was unsatisfactory in at least two respects.

First, it did not adequately address what turned out to be a fundamental difference of approach between the experts as to whether a system can be said to be “functional” if the alleged deficiencies relate to elements which can reasonably be expected to be the subject of discussion and further agreement between the parties. Thus, the fundamental dichotomy between Dr Kovačević and Dr Hunt centred not so much on whether certain functionalities were or were not present in the Digital Capital system, as on whether they were functionalities that Digital Capital could have been expected to provide without further input from Genesis. Dr Kovačević said they were not. In his view, the Digital Capital system was a test system ready for integration and any additional or extended functionality was a matter for discussion and agreement. By contrast, Dr Hunt accepted that some further collaboration would have been necessary in relation, for example, to integration, but said that the system should nonetheless have contained all or nearly all of the functionality envisaged by the Agreement. There should not have been substantial gaps and defects and, in her view, none of the deficiencies she identified was in fact dependent on integration.

Secondly and perhaps more fundamentally, “functioning” is not a term of art and has no industry accepted definition. Dr Hunt therefore applied her expert view of industry norms. However, it is not immediately clear to me that this is the correct yardstick when “functioning” is not a defined term and, indeed, has no contractual relevance whatsoever. Nor was there any pleaded case by either party which referred to any obligation to deliver a “functioning system”.

Mrs Arlov put it to Dr Hunt that if the Digital Capital system was acceptable to the regulator and to Genesis, then it should be regarded as “functioning” irrespective of what Dr Hunt or anyone else in the industry might think. It is difficult to argue against that bald proposition, although Dr Hunt said (as she was entitled to do) that she would not have expected certain of the alleged deficiencies to be acceptable to either the regulator or Genesis.

Nevertheless, as she accepted, the Digital Capital system did function and each of the allegedly missing or incomplete functionalities was capable of remedy. It was accordingly not like a car which fails to start when the key is turned, nor, to extend the metaphor, like a car which is a complete write-off. However, it seemed to me that it was an impossible task for either expert to express an opinion on whether this was a “functioning system” for the purposes of this contract and these parties without giving them a meaningful definition of “functioning” in this context.

In short, the question as posed did not really assist me in determining whether Digital Capital was in breach as alleged or not. In my judgment it is necessary rather to go back to basics and ask what it was that Digital Capital was required under the terms of the Agreement to provide and the timescale within which it was required to provide it. The views of the experts were undoubtedly helpful to me in that context.

Under clause 3.1(f) of the Agreement, Digital Capital’s obligation was to exercise reasonable care and skill in providing its services. The content of those services was set out in Appendix 1 to the Agreement. This contained three sections. The first dealt with regulatory set-up as to which no issue arises. The second covered the software set-up and specified a number of different modules, each with various requirements. The third section related to on-going operational support and system maintenance. The crux of the dispute between the parties was whether Digital Capital had satisfied the requirements of the second section as at 3 June 2019.

The principles of contractual construction are by now too well-known to bear extensive repetition. For present purposes I am happy to adopt the summary set out by Popplewell J (as he then was) in The Ocean Neptune, [2018] EWHC 163 (Comm); [2018] 1 Lloyd’s Rep. 654 at [8]:

I also bear in mind that, as already noted, the Agreement was drafted by Digital Capital and that Mr Dolić did not read it in any detail before signing it. The contents of Appendix 1 can only therefore have been compiled on the basis of Digital Capital’s assumptions as to what would be required following its discussions with Genesis. The fact is, however, that both parties signed the Agreement and are therefore bound by its objective meaning irrespective of what either of them may have thought it meant.

One of the problems in construing the requirements of Appendix 1 was the lack of any industry-wide consensus on standard definitions for various terms and concepts such as might be contained in some sort of handbook. In Dr Hunt’s words, the IT industry “coins terms willy-nilly”, and some caution was therefore required in interpreting them. Dr Hunt also regarded Appendix 1 as being towards the lower end of the scale in terms of specificity. This again leaves considerable scope for interpretation and she accepted that discussion and collaboration would be both required and expected in the normal course in order to refine the requirements set out in Appendix 1. She accepted that an analogy with the Channel tunnel was apt, where construction was started from both ends simultaneously and close liaison was necessary to ensure that they met correctly in the middle.

It was likewise not in dispute that Digital Capital could not, on its own, achieve integration of its platform with the Genesis crypto platform. Technical specifications would need to be provided by Genesis for that purpose. I am also prepared to accept that the process of integration might itself have required changes to the Digital Capital system and that it would not necessarily have been sensible for Digital Capital to attempt to finalise certain aspects of its system until integration had taken place.

I regard all of this as part of the relevant factual matrix in which the Appendix 1 falls to be construed.

As to timescale, clause 3.1(d) of the Agreement provided that Digital Capital was to use its reasonable endeavours to achieve a Go Live date by 10 July 2018. Clearly that date was not achieved and Mr Bergin accepted that unless time was made of the essence (which it was not), Digital Capital’s obligation thereafter was to deliver its part of the system within a reasonable time.

In my judgment, taking all these matters into account, from and after 10 July 2018 Digital Capital’s overarching obligation was to exercise reasonable skill and care to make available⁵ within a reasonable time an adequate structure to support the functionalities required under Appendix 1 which was in a sufficiently developed state for user acceptance testing (“UAT”) and integration to take place. In broad terms this meant that the system had to be capable of providing all the required functionalities (apart from those which depended on integration) even if some of them may have needed further refinement or improvement in the light of Genesis’ specific requirements.

In assessing the functionality of the Digital Capital system, I am prepared to assume in Digital Capital’s favour that the system which LMG delivered in July 2018 had the same functionality as the system which was inspected by the experts in 2021. In other words, I assume that there were no material changes after July 2018 other than a change

Conversely, I assume in favour of the Defendant that a reasonable time for discharge of Digital Capital’s obligations had expired by 3 June 2019.

I accept that Digital Capital considered that the system provided in July 2018 met all the requirements of the Agreement save for those which depended on integration or further information from Genesis. However, the experts disagreed on this point. While there was a measure of consensus between them as to what the system comprised, they differed as to whether in certain respects it did or did not comply with the Agreement.

These differences were very helpfully summarised in a table appended to the Expert Joint Memorandum. In order not to over-burden this judgment unduly, and in view of my ultimate conclusion that Digital Capital was not in repudiatory breach, even though the system provided did not contain all the functionality required by Appendix 1, I do not propose to address each item in detail. My brief findings based on my assessment of the evidence are set out in a separate Appendix B to this judgment.

Where I have found that the system failed to provide certain functionalities, this was generally for one of three reasons:

In the case of category ii), provision of functionality depended in many cases on ascertaining Genesis’ precise requirements. Clause 4.2 of the Agreement required Genesis Iceland to provide all reasonable assistance requested by Digital Capital to enable it to perform its services. The question therefore arises whether Digital Capital can be said to have exercised the reasonable skill and case required by the Agreement without asking specifically for the information which it required. However, Digital Capital had expressly and repeatedly asked for over a year to be provided by Genesis/Barrage with the technical specifications necessary for integration and also for functional specifications.⁶ The most recent request was at the meeting on 24 March 2019 when it was left that Mr Endriss would co-ordinate a further meeting between Digital Capital and Barrage. According to Mr Kaiser’s note, a development meeting was also to be organised with Barrage during the first week in April 2019. I bear in mind that these proposed meetings with Barrage would have been the first occasion on which the entire Digital Capital system would have been examined by anyone with the requisite technical knowledge, Barrage having previously only tested the payment

In my view, Digital Capital could therefore reasonably have assumed that it would be able to demonstrate its system at those meetings and address any outstanding functionalities or technical glitches thrown up as a result. The meetings were, of course, never in fact organised by Mr Endriss.

Likewise with category iii). If Genesis was unhappy about the manner in which some functionality had been provided or the absence of specific safeguards, this again was something which could reasonably have been expected to be addressed during the development discussions and also during testing and integration.

The same cannot be said about the category i) deficiencies, however. These are all functionalities which were not supported by the system developed by Digital Capital. In my view, they were functionalities which should have been provided – or at least enabled – irrespective of the need for integration or further input from Genesis. To that extent, and assuming in the Defendant’s favour that a reasonable time had expired by 3 June 2019, I find that Digital Capital was at that date in breach of the Agreement in these respects.

Although there is no contractual definition of what constitutes a “material breach”, I accept Dr Hunt’s evidence that these were all material breaches which a client would require to be remedied. However, the question I have to determine is not whether they were material breaches, but whether they were repudiatory.

As to this, I have formed the clear view that even if Digital Capital was in material breach in all the respects alleged by the Defendant (and not just the category i) deficiencies that I have found to be established) it was nonetheless not in repudiatory breach. I say this for the following reasons:

For these reasons, I conclude that Digital Capital was not in repudiatory breach of the Agreement as at 3 June 2019 in the respects alleged.

Mr Bergin’s alternative case was that Digital Capital was in repudiatory breach in failing over a long period of time to provide financial information in response to reasonable requests by Genesis or to evidence the state of development of its system.

I cannot accept either submission. On the basis of my factual findings set out above, there was no detailed request for any financial information until Mr Kaiser’s email of 27 November 2018. However, as I have found, that email was sent in the context of a potential investment by outside investors. Genesis may have had other reasons for wanting the information but these were not made explicit. In any event, it was conceded by Mr Bergin that those reasons were nothing to do with the Agreement itself.

It is therefore difficult to discern any basis on which it can be said that the failure to provide the information was repudiatory of the Agreement. On the contrary, a degree of circumspection on the part of Digital Capital in ensuring that information was only disclosed to the extent that the recipient had an entitlement to receive it was entirely understandable. I accept that the question of the shareholdings in Digital Capital was something of a running sore, but I equally accept that it was not unreasonable for Mrs Arlov and Mr Perković to suggest that this was a matter more appropriately addressed after the system had gone live. They were not to know until disclosure of the Genesis group’s financial difficulties at the end of 2018 that completion of the project would be

However, the short and decisive answer to the point is that the allocation of shares in Digital Capital was contractually irrelevant to the performance of the Agreement.

As regards the alleged failure to provide evidence as to the state of development of the Digital Capital system, this is effectively disposed of by my findings at paragraphs 200- 205 above. As far as Digital Capital was concerned, its system had been completed as far as possible. Two presentations had been given in 2018 to which the Defendant had chosen not to send any technical people. Digital Capital was expecting to meet Barrage soon after the 24 March 2019 meeting for the specific purpose of discussing the system in depth. I can see no tenable basis on which it can be said in these circumstances that it was unwilling to provide evidence as to the state of development of its system.

In conclusion, taking the Defendant’s case on functionality at its highest and even accepting that a reasonable time had expired by 3 June 2019, I hold that Digital Capital was not in repudiatory breach of contract and that the Defendant was not entitled to terminate the Agreement as it purported to do. It necessarily follows that the Defendant was thereby itself in repudiatory breach of contract.

I accordingly answer the issues set out at paragraph 160 above as follows:

In the premises, the Claimant’s claim for payment of its outstanding invoices in the sum of £2,484,046 succeeds.

The Claimant has claimed contractual interest at the rate of 3.75% per annum accruing on a daily basis and compounding quarterly. I assume that this is pursuant to clause 19 of the Agreement which provides for interest at 3% above the RBS base rate for the time being from the due date until the date of payment. However, neither party addressed me on interest or costs and I will therefore allow an opportunity for further submissions before making any order on either matter.

Assessment of any damages sustained by the Claimant as a result of the Defendant’s repudiation of the Agreement is to be determined hereafter at the second trial contemplated in the Order of 15 May 2020. That Order provides for directions for the second trial to be given following determination of the first trial and I accordingly invite the parties to agree appropriate directions if possible.